Thursday, March 28, 2024
47.0°F

Legals for May, 15 2020

| May 15, 2020 12:00 AM

NOTICE TO CONTRACTORS SEAL COAT PROJECT - 2020 Moses Lake, Washington Sealed bids will be received at the Civic Center Annex, 321 South Balsam, (P. O. Box 1579), Moses Lake, Washington 98837 until JUNE 10, 2020; 2:00 PM, for the above-named improvement. Said bids will be opened and publicly read at that time. All bids shall be received before said opening time in sealed envelopes with SEAL COAT PROJECT - 2020 marked plainly thereon. All bids shall be accompanied by a deposit in the form of a postal money order, cashier's check, or bond in an amount equal to 5 percent of the maximum total amount of the bid. Should the successful bidder fail to enter into a contract or furnish a satisfactory contract bond within the time stated in the specifications, the deposit shall be forfeited to the City. Plans and specifications may be obtained at no cost via electronic transmission from the City of Moses Lake. Paper copies of the plans and specifications may also be obtained from the Civic Center Annex at the above address for a non-refundable fee of $ 30 . Plans and specifications can be requested by responding to this email, or by calling the Contact person listed below during normal business hours. Copies of plans and specifications are on file for review at various construction councils. All bidders shall call 509-764-3786 prior to bid opening to sign up as a bidder on the project, whether or not they request a hard copy or obtain a digital copy of the Specifications. Bids received from bidders who are not signed in as a bidder on the project will be rejected for being non-responsive. Contact person: Jeff Holm; 509.764.3781; jholm@cityofml.com PROJECT DESCRIPTION: This project includes completing approximately 7,600 SY with a 5/8" - No. 4 seal coat and 170,000 SY with a 3/8" - No. 10 seal coat followed by a fog seal on streets within the City of Moses Lake. Other work includes applying temporary raised pavement markings, sweeping, utility adjustments, flushing streets, brooming, pavement markings, and traffic control. The emulsified asphalt to be used is CRS-2P. Estimated Project Cost: $750,000 Contract Working Days: 40 The City Council reserves the right to reject any or all bids if such action is in the best interest of the City. #05031/381962 Pub: May 15, 18, 2020

EPHRATA SCHOOL DISTRICT - PARKWAY SCHOOL OFFICE REMODEL INVITATION TO BID EPHRATA SCHOOL DISTRICT No. 165 DESIGN WEST ARCHITECTS 111 4th Avenue NW9 05 West Riverside Avenue, Suite 605 Ephrata, WA 98823 Spokane, WA 99201 You are invited to bid on a General Contract for construction in the City of Ephrata for the construction of the Parkway School Office Remodel. The project consists of a renovation of the existing Parkway school office approximately 1,000 SF. The work includes Structures, Finishes, Mechanical, and Electrical work. Preliminary Estimate: Base Bid: $115,000 Proposals will be accepted by the District until 1:00pm, prevailing time, on Thursday, May 28, 2020 at the Ephrata School District Professional Development Center at 357 Alder St., Ephrata, WA 98823. Base Bid and Alternate proposals will be opened publicly and read aloud at 1:00pm. Interested parties are invited to attend. A Virtual Pre-Bid Conference, optional for all General Contractor prospective bidders, will be held Wednesday, May 20, 2020 at 11:00 am. Plans and Specifications are available, beginning May 12, 2020, through the Architect. E-mailed PDF drawings and specifications are available at no cost. Printed paper sets are available at $200 per set (limit 1 sets to General Contractors and 1 set for subcontractors). The cost is refundable provided the documents are returned in good condition within 10 days after bid opening to the office of the architect. Additional sets may be purchased at cost, non-refundable. Contact Katie Fairbanks, Office Administrator with Design West Architects by e-mail at kfairbanks@designwestpnw.com to request documents. Bid security amounting to five percent (5%) of the total Base Bid must accompany each Bidder's proposal in accordance with Instructions to Bidders. Bid documents will be available for examination during the bidding period at the following locations: Abadan Regional Plan Center -Spokane, WA Associated Builders & Contractors, Inc. - Spokane, WA Builders Exchange of Washington - Everett, WA CMD Group - Norcross, GA Contractor Plan Center, Inc. - Milwaukie, OR Dodge Data & Analytics - Seattle, WA Daily Journal of Commerce Plan Center - Seattle, WA Hermiston Plan Center - Hermiston, OR iSqFt + Bidclerk - Chicago, IL Southwest Washington Contractors Association - Vancouver, WA Spokane Regional Plan Center - Spokane, WA Tri-City Construction Council - Kennewick, WA Walla Walla Valley Plan Center - Walla Walla, WA Wenatchee Plan & Copy Center - Wenatchee, WA Yakima Plan Center - Yakima, WA No bidder may withdraw his proposal after the date and time set for opening thereof or before Award of Contract, unless said award is delayed beyond 30 days. Substantial Completion shall be achieved in compliance with Section 01 10 00 of the project specifications. The project requires compliance with prevailing wage under RCW 39.12 and apprenticeship participation of 15% under RCW 39.04.320. The District reserves the right to accept or reject any or all proposals, and in particular, to reject a proposal not accompanied by the required bid security or data required. The process shall comply with WAC 180-29-105, RCW 28A.335.190 and RCW 43.19.1906. #05021/380878 Pub: May 8, 15, 2020

Notice to Heirs of Casey Dillard, Marcie Dillard Estate of Tamera Dillard The following information is furnished in accordance with the provisions of ORS 113.145 to Marcie Dillard and/or the heirs of Casey Dillard (deceased spouse of Tamera Dillard). Tamera Dillard, the decedent, died on June 15, 2015, in Grants Pass, Josephine County, Oregon. Estate proceedings in Tamera Dillard's estate, bearing the clerk's file number 19PB07436, have been commenced and are now pending in the Circuit Court of the State of Oregon for the County of Josephine, Department of Probate. On October 23, 2019, Daron McGlothlin, whose address is CMR 450, box 664, APO AE 09705 (Belgium), was duly appointed and is now serving as personal representative of the estate. Your rights may be affected by this proceeding; additional information may be obtained from the records of the court, the undersigned personal representative, or the attorney for the personal representative, Stephanie Carter, Hilary Carter Law, 9250 SW Tigard St., Tigard, OR 97223. If you wish to receive copies of future filings in this case, you must inform the court and the attorney for the personal representative of this notice. You must inform the court by filing a request for notice and paying the applicable fee, if any. The request for notice must be in writing, must clearly indicate that you wish to receive future filings in the proceedings, and must contain your name, address, and phone number. You must notify the attorney for the personal representative by mailing a true copy of the request to the attorney. Unless you take these steps, you will receive no further copies of the filings in this case. NOTICE - WRONGFUL DEATH SETTLEMENT: The personal representative for the estate of Tamera Dillard has filed his PETITION FOR ORDER APPROVING SETTLEMENT, APPORTIONMENT, PERSONAL REPRESENTATIVE'S FEE, AND ATTORNEY'S FEES AND COSTS. Any objections to the Petition must be filed with the court in the estate proceeding on or before June 19, 2020. If an objection is filed, the court will hold a hearing. At this time, no hearing has been set. #06001/381829 Pub: May 15, 22, 29, 2020 & June 5, 2020

Othello School District No. 147 Request for Fuel Bid The Othello School District is accepting bids for Fuel (diesel & unleaded) for the 2020-2021 school year. Bids will be accepted until 9:00 a.m., Thursday, May 28, 2020. Submit sealed bids to Othello School District, Attn: Sheree Cantu, 1025 S. 1st Avenue, Othello, WA 99344. Bids are to be in a sealed envelope clearly marked "Fuel Sealed Bid". For Specifications, please contact Sheree Cantu at the Administration office at (509) 488-2659, Ext. 1031, SCantu@othelloschools.org. _________________________ Kenneth C. Hurst Sr., Superintendent #05005/378988 Pub: May 11, 13, 15, 18, 20, 22, 2020

Othello School District No. 147 Request for Dairy Products The Othello School District is accepting bids for dairy products for the 2020-2021 school year. Bids will be accepted until 9:00 a.m., Thursday, May 28, 2020. Submit sealed bids to Othello School District, Attn: Sheree Cantu, 1025 S. First Avenue, Othello, WA 99344. Bids are to be in a sealed envelope clearly marked "Dairy Sealed Bid". For specifications, please contact Sheree Cantu at the Administration office at (509) 488-2659, Ext. 1031, SCantu@othelloschools.org. ___________________________________ Dr. Kenneth C. Hurst, Superintendent #05006/379040 Pub: May 11, 13, 15, 18, 20, 22, 2020